Privacy and DisclaimerKen Kelly
Kelly Roofing respects the privacy of our customers and visitors. While we may collect specific personal or professional information such as name, title, mailing address, email, etc., we use this data internally only. These examples are illustrations and are not all-inclusive. No information is provided to outside parties for any purpose.
You can also be taken off our mailing list about future promotions and offers by sending an e-mail message to: KellyGroup@KellyRoofing.com. If you would like to make sure that the information we do have about you is accurate or wish to change your information in our database, just send an email message explaining the correction or change to:KellyGroup@KellyRoofing.com.
Notwithstanding the above, with respect to all users of our site, Kelly Roofing reserves the right to disclose any content, records, or electronic communication of any kind (including personal information or private electronic communication transmitted on our site):
(i) to satisfy any law, regulation, or government request;
(ii) if such disclosure is necessary or appropriate to operate kellyroofing.com; or
(iii) to protect the rights or property of Kelly Roofing or its users, providers, licensors, or merchants. Kelly Roofing also reserves the right to reject any order or to request additional information from any customer.
The information contained on this website is intended to provide information and be educational. The information provided may not pertain to your specific issue, should not be construed as fact or an expert opinion and does not constitute advice on any issue. The visitor, by exploring this website, communicating via the methods available on the website or through other means, or using links to the company website, agrees that no business relationship will be created except by a written agreement.
General Contract Agreement
1.General. This proposal (“Agreement”) is subject to change without notice and is automatically withdrawn on the 15th day following the date of issue if not accepted in writing and a copy of this proposal returned to KELLY ROOFING, LLC (“Contractor”). If Customer cancels this Agreement prior to the start of work, and not before midnight of the third business day after Customer signs this Agreement, Customer is liable for 15% of the total Agreement price as liquidated damages because Contractor is unable to accurately measure its damages for the cancellation of the Agreement. By executing this Agreement, Customer and Contractor agree that the liquidated damages amount is not a penalty. Contractor reserves the right to withdraw this proposal at any time prior to its acceptance or to cancel this Agreement prior to commencing work if the cost to complete the work varies from the initial standard pricing due to a typographical or mathematical error. As used in this Agreement, (a) the word “or” is not exclusive, (b) the word “including” is always without limitation, (c) “days” means calendar days and (d) singular words include plural and vice versa.
2.Access. Customer shall provide Contractor with adequate access to electricity and other utilities as needed, the work site, and the work area adjacent to the structure. Contractor disclaims any and all liability for the grading, leveling, slope or construction of the roof deck, the roofing system, structure and/or appurtenances. Customer represents to Contractor that all of the existing surfaces are suitable to receive the materials identified in the scope of work. Customer shall provide Contractor with access to deliver and/or remove materials and debris. Prior to the commencement of work, Customer shall provide Contractor with access to the interior of the structure, upon reasonable notice by Contractor, to inspect the premises for stains, ceiling damage and/or structural damage. Contractor shall not be responsible for any preexisting stains, ceiling damage and/or structural damage. Customer shall provide Contractor with all information necessary to prepare the Notice of Commencement. Customer and/or owner shall hold harmless and indemnify Contractor from all damages, liabilities, attorney’s fees and other expenses incurred as a result of the Customer and/or Customer’s failure to fulfill its obligations under this paragraph.
3.Payment Terms. By signing this Agreement, Customer gives Contractor the right to obtain a credit check on the signatory. Contractor reserves the right to require a deposit in excess of 10%, and Customer hereby waives the requirements of Florida Statute 489.126. Customer agrees to pay interest at the rate of 1 1/2 % per month (ANNUAL PERCENTAGE RATE OF 18%), unless otherwise required by law, on the balance of any and all unpaid amounts. Payments received shall be applied first to interest on all outstanding invoices and then to the principal amount of the oldest outstanding invoices. The total Agreement amount, including the charges for changes/extras outside the scope of work identified herein, shall be payable to Contractor in accordance with the Agreement. No portion of the agreed upon payment may be withheld, back charged or used as a setoff of the agreed upon payment amount without the written consent of Contractor. Customer acknowledges and agrees that it has an independent obligation to pay Contractor. If Customer does not make payment, Contractor shall be entitled to recover from Customer all costs of collection incurred by Contractor, including attorney’s fees, costs, and expenses incurred whether or not litigation is initiated. Collection matters may be processed through litigation or arbitration at Contractor’s sole discretion. If there is an increase in the price of materials charged to the Contractor in excess of five (5%) percent, subsequent to making this Agreement, then the price set forth in this Agreement shall be increased without the need for a written change order or amendment to the Agreement to reflect the price increase and additional direct cost to the Contractor. Contractor shall submit written documentation of the increased charges to the Customer. If Customer fails to pay Contractor in accordance with this Agreement, then Contractor may, at its sole discretion, suspend performance of all work, suspend shipments and/or warranties until full payment is made, and/or terminate this Agreement. If a suspension occurs that is not caused solely by the Contractor, the Agreement sum shall be increased by the amount of contractor’s reasonable costs of shut-down delay and start-up. The parties acknowledge and agree that the substitution of materials and price adjustments may be required based on changes in material availability and the cost to obtain and deliver materials to the project between the date of this Agreement and the delivery date. In such event, Contractor and Customer shall work together in good faith to identify substitute materials that are similar in price and quality and that do not cause an increase to the Agreement amount. If Customer selects substitute materials that increase the Agreement amount, then the Agreement will be adjusted to reflect the additional costs incurred by the Contractor to purchase and deliver the materials.
4.Site Conditions. Should the Contractor discover concealed or unknown conditions in the existing structure that vary from those conditions ordinarily encountered and generally recognized as inherent in the work of the character identified in this Agreement, then the Agreement amount shall be equitably adjusted upon notice thereof from the Contractor to the Customer.
5.Sealed Attic Liability Exclusion: Contractor shall not be liable for any roof or structural related issue arising out of or relating to combining a sealed attic system with a self-adhered underlayment, and Customer agrees to indemnify and hold harmless Contractor for any and all damages arising out of said condition.
6.Restrictions and Requirements. Contractor shall carry worker’s compensation, automobile liability, commercial general liability and any other insurance required by law. In the event that state, county, or municipal codes or regulations require work not expressly set forth in this Agreement or that differs materially from that generally recognized as inherent in work of the character provided for in this Agreement, all extra costs for Contractor’s labor and materials shall be the sole obligation of the Customer. If the substrate roof condition results in ponding pursuant to the Building Code and modifications are required to correct the roof so ponding will not occur, Contractor will notify Customer immediately. Prior to executing this Agreement, Customer shall notify Contractor in writing of all property and deed restrictions and/or covenants that relate to or restrict the improvements contained in this Agreement. Contractor shall not be responsible for work performed that does not comply with or conform to the property restrictions or covenants. Customer shall pay Contractor for all work performed in violation of any covenant or restriction if Customer failed to notify Contractor in writing prior to executing this Agreement.
7.Customer Protection of Property. Customer shall be solely responsible for any damage to curbs, walkways, driveways, structures, septic tanks, HVAC, utility lines, pipes, gutters, landscaping, appurtenances, or other real or personal property at the project location during construction. Contractor shall not be responsible for cracks of any kind in the ceiling due to the performance of Contractor’s work on the property. Contractor shall not be responsible for any damage caused by dust or debris caused by Contractor’s work. Contractor shall not be responsible for damage to person(s) or property caused by nails on the property. Customer shall take the appropriate precautions to protect the property and to avoid damages or injury caused by nails. Contractor’s warranty does not include roof tile slippage on a mortar or foam type tile roof system on roofs with a pitch greater than 4/12 that are not mechanically fastened. Customer agrees that under no circumstances shall Contractor be held liable for water intrusion, or any damage caused by same, that occurs from the date Contractor commences work on the project through the date of completion of such work. Customer shall be responsible for removing, installing, and re-positioning satellite dish(es), solar panel(s), lightning rod(s), etc. Customer shall be responsible for damage to lighting fixtures, mirrors, pictures, frames, and other such items not customarily permanently affixed, as these items can fall if not firmly attached to the wall or ceiling. Customer shall secure and protect all personal items in advance of construction and shall protect or remove all wall hangings until the work is complete. Contractor shall not be responsible for lost, stolen, or damaged personal items and wall hangings. Unless otherwise specified, there is no specific completion date for Contractor’s work. Contractor will perform the work within a reasonable time and in a workmanlike manner. The cost for testing and abatement of asbestos and lead is the sole responsibility of the Customer. As part of the roofing process, odors and emissions from roofing products will be released and noise will be generated. Customer shall be responsible for indoor air quality during the work and shall hold Contractor harmless, indemnify and defend Contractor from any and all claims, actions, proceedings, and complaints arising out of or relating to fumes, odors, and/or the indoor air quality during Contractor’s performance of the work. If Customer requests Contractor to install permanent safety brackets to the subject roofing system, Customer hereby authorizes Contractor and its subsidiaries, affiliates, employees, agents, suppliers, and subcontractors to have sole access to use the safety brackets during Contractor’s performance of the work. Accordingly, Customer hereby releases, acquits and forever discharges, and shall indemnify and defend Contractor from any and all claims, demands, damages, rights, and causes of action of every kind, nature and description whatsoever, arising out of or by reason of or in any manner connected with the unauthorized use of the safety brackets by the Customer or any third party.
8.Choice of Law, Venue and Attorney’s Fees. This Agreement shall be governed by the laws of the State of Florida. Venue of any proceeding arising out of this Agreement shall be Collier County, Florida. The non-prevailing party in any legal or equitable action arising out of or relating to this Agreement including arbitration, administrative, appellate and/or bankruptcy proceedings shall reimburse the prevailing party on demand for all attorney’s fees, costs, and expenses incurred by the prevailing party in connection with the action.
9.Arbitration. If a dispute shall arise between Contractor and Customer with respect to any matters or questions arising out of or relating to this Agreement or the breach thereof (other than collection matters), such dispute, at Contractor’s sole discretion, may be decided by arbitration administered by and in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association. This Agreement to arbitrate shall be specifically enforceable under the prevailing arbitration law. The award rendered by the arbitrators shall be final, and judgment may be entered upon it in any Court having jurisdiction thereof.
10.Jury Trial Waiver. In the event of litigation between the parties to this Agreement, the parties KNOWINGLY, VOLUNTARILY, IRREVOCABLY AND INTENTIONALLY WAIVE THE RIGHT TO A TRIAL BY JURY IN RESPECT TO ANY LITIGATION ARISING OUT OF OR PERTAINING TO THE AGREEMENT, OR ANY COURSE OF CONDUCT, COURSE OF DEALINGS, STATEMENTS (WHETHER VERBAL OR WRITTEN) OR ACTIONS OF ANY PERSON OR PARTY RELATED TO THIS AGREEMENT; THIS IRREVOCABLE WAIVER OF THE RIGHT TO A JURY TRIAL BEING A MATERIAL INDUCEMENT FOR THE PARTIES TO ENTER INTO THIS AGREEMENT
11.Damage Limitation. In no event, whether based on contract, warranty (express or implied), tort, federal or state statute or otherwise arising from or relating to the work and services performed under the Agreement, shall Contractor be liable for special, consequential, punitive, or indirect damages, including loss of use or loss of profits. Contractor and Customer agree to allocate certain of the risks so that, to the fullest extent permitted by law, Contractor’s total aggregate liability to Customer is limited to the dollar amount of the Agreement for any and all injuries, damages, claims, expenses or claim expenses including attorneys’ fees arising out of or relating to this Agreement regardless of whether it is based in warranty, tort, contract, strict liability, negligence, errors, omissions, or from any other cause or causes.
12.Warranties. Unless otherwise provided: THERE ARE NO EXPRESS OR IMPLIED WARRANTIES WHATSOEVER INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANT-ABILITY AND FITNESS FOR A PARTICULAR PURPOSE. All warranties/guarantees provided by Contractor, if any, shall be deemed null and void if Customer fails to strictly adhere to the payment terms contained in the Agreement. All warranties and guarantees, if any, provided under the Agreement are solely for the original Customer and are non-transferable, unless otherwise agreed to by Customer and Contractor in writing. Any express warranty provided, if any, by Contractor is the sole and exclusive remedy for alleged construction defects, in lieu of all other remedies, implied or statutory. Warranties to be issued upon completion and full payment of this Agreement. If there is a breach in the applicable Manufacturer’s warranty according to the stated terms and conditions of the warranty supplied, at that moment, this would simultaneously void Contractor’s warranty and all of Contractor’s responsibility and liability to correct, supplement, rectify, fix, etc. any and all issue(s) as a result of the breach in the Manufacturer’s warranty.
13.Claims.It is Customer’s duty to notify Contractor in writing within three (3) days of the occurrence of any claim, defect or deficiency arising out of work, services or materials provided by Contractor under this Agreement (“Occurrence”). Failure of the Customer to provide written notice of the Occurrence shall result in the Customer waiving all claims that may be brought against Contractor arising out of or relating to the Occurrence, including claims arising in law, equity, contract, warranty (express or implied), tort or federal or state statutory claims.
14.Acts of God; Delay. Contractor shall not be responsible for loss, damage or delay caused by circumstances beyond its reasonable control, including but not limited to acts of God, weather, accidents, fire, vandalism, federal, state or local law, regulation or order; strikes, jurisdictional disputes, failure or delay of transportation, shortage of or inability to obtain materials, equipment or labor; changes in the work and delays caused by others. In the event of these occurrences, Contractor’s time for performance under this Agreement shall be extended for a time sufficient to permit completion of the Work.
15.Unforeseen Decking Lines. Installation of a new roof to the deck area of the building requires nails and/or screws to be inserted into the deck area. By code, electrical, telephone and security wiring and air conditioning wiring and lines should not be installed directly beneath the roof deck. If Customer is aware of these or any other such lines, Customer must notify Contractor immediately as the Contractor will not be responsible for the puncture of improperly installed lines or lines within three inches of the roof deck. Customer accepts full responsibility for any repair or replacement that may be necessary.
16.Customer Delay. The Parties agree that the Contractor should be permitted to execute its work without interruption. If Contractor’s work is delayed at any time by any act or neglect of Customer and/or Customer’s representatives, employees, agents, guests, or invitees, or any other contractor employed by the Customer, or by any changes ordered in the work, then Contractor shall be reimbursed or paid for all additional costs or damages incurred as a result. This shall include damages related to lost use of equipment caused by the delay.
17.Disclaimer. Contractor disclaims all liability for all claims, disputes, rights, losses, damages, causes of action or controversies (“Claims”) pertaining to mildew, algae, fungus, mold, and/or other indoor air allergens (“Mold”) including Claims arising out or relating to the detection, removal, disposal, or remediation of Mold, whether those Claims arise in law, equity, contract, warranty, tort, or federal or state statutory claims, and whether those Claims are based on the acts or omissions of Contractor or individuals or entities under Contractor’s control. The Customer is solely liable and responsible for all damages, whether actual or consequential, caused by Mold and incurred by Customer, Contractor or third parties, and agrees to indemnify and hold harmless Contractor from any and all Claims arising out of or relating to Mold.
18.Pre-Existing Conditions. Customer acknowledges that Contractor will be repairing work that was previously damaged by mold, water, termites, or other conditions (“Pre-Existing Conditions”) unrelated to the work performed by Contractor. Accordingly, Contractor disclaims all liability for all claims, disputes, rights, losses, damages, causes of action, or controversies (“Claims”) pertaining to Pre-Existing Conditions, whether those Claims arise in law, equity, contract, warranty, tort, or federal or state statutory claims. Customer is solely liable and responsible for all damages, whether actual or consequential, arising out of or relating to Pre-Existing Conditions.
19.Working Hours. The Agreement is based upon the performance of all work during Contractor’s regular working hours, excluding weekends and National holidays. Extra charges will be made for overtime and all work performed other than during Contractor’s regular working hours if required by Customer.
20.Materials. All materials and work shall be furnished in accordance with normal industry tolerances for color, variation, thickness, size, weight, amount, finish, texture and performance standards. Specified quantities are intended to represent an average over the entire roof area. Contractor is not responsible for the actual verification of technical specifications of product manufacturers, i.e., R value, ASTM or UL compliance, but rather the materials used are represented as such by the manufacturer. Metal roofing and especially lengthy flat span sheet metal panels will often exhibit waviness, commonly referred to as “oil-canning.” Oil-canning pertains to aesthetics and not the performance of the panels and is not controlled by the Contractor. Contractor is not responsible for oil-canning or aesthetics. Oil-canning shall not be grounds to withhold payment or reject panels of the type specified. Title to roofing products passes to the Customer when said products are delivered to the job site. In the event of impending high wind conditions, hurricanes, tornadoes, or other adverse weather conditions, if Contractor is requested to remove/re-position product from/on the job site, Contractor shall use its reasonable efforts (subject to weather conditions, life/safety concerns and manpower/equipment constraints) to comply with the request. Customer agrees to promptly pay Contractor for these extra services. Contractor is not responsible for defective products if Contractor did not know such products were defective prior to the installation of same. As such, Contractor is not responsible for any costs, damages, claims, etc., associated with any remediation of supposed harm caused by a defective product. A defective product shall not be grounds to withhold payment or reject the work performed by Contractor.
21.Construction and Interpretation. Each provision of the Agreement shall be construed as if both parties mutually drafted this Agreement. If a provision of this Agreement (or the application of it) is held by a court or arbitrator to be invalid or unenforceable, that provision will be deemed separable from the remaining provisions of the Agreement, will be reformed/enforced to the extent that it is valid and enforceable, and will not affect the validity or interpretation of the other provisions or the application of that provision to a person or circumstance to which it is valid and enforceable. Headings are for convenience only and do not affect interpretation. This Agreement records the entire agreement of the parties and supersedes any previous or contemporaneous agreement, understanding, or representation, oral or written, by the parties. All documents/exhibits referred to in this Agreement are an integral part of the Agreement and are incorporated by reference. This Agreement specifically incorporates the documents entitled “Proposal/Contract,” “Statutory Warnings,” “Limited Workmanship Warranty” (if applicable), and “Work Authorization” (if applicable), as well as any other document issued to Customer by Contractor and intended to be a part of this Agreement (the “Contract Documents”). Customer represents that he or she has read and fully understands the Contract Documents and has been provided the opportunity to consult with counsel of his or her choosing prior to executing this Agreement. In the event of a conflict between this Agreement and any other Contract Document, the order of precedence is Work Authorization (to the extent it exists) followed by these terms and conditions.
22.Drone Disclaimer. Customer agrees that Contractor and/or any related entities, supplier, subcontractor, or vendor may use a drone or other aerial device to take photos and/or videos if Customer’s property. Customer hereby allows Contractor to use any images or video footage obtained for promotional, legal, or any other use as desired by Contractor. In consideration for the added benefit received by Customer by way of Contractor’s use of the aforementioned technology, Customer agrees to hold Contractor harmless for any unintentional damage caused by the use of a drone to Customer’s real or personal property.
23. Use of Photo and Likeness. I consent to photographs/videos/images being taken of my residence and agree to allow my photo, video, or likeness to be used for any legitimate purpose by Kelly Roofing or its partners, producers, sponsors, organizers, and assigns, including but not limited to promotional and marketing uses.
All work is to be completed in a workmanlike manner according to standard practices. Any change or deviation from the scope of work identified herein that results in additional cost to Kelly Roofing, LLC (“Contractor”), will be charged to the Customer as a cost that is separate from and in addition to the quoted price. Contractor’s employees will be covered by Worker’s Compensation Insurance. If there are any persons or materials, other than Contractor’s employee(s) or the materials supplied by Contractor to perform Contractor’s scope of work, on the roof during the project or after the Contractor has completed its work, then any warranty issued by Contractor to Customer for the project will immediately become null and void without exception. The Contract Documents consist of this Proposal/Contract, the Terms and Conditions and all documents referenced therein, the Statutory Warnings, the Work Authorization (if applicable), and the Limited Workmanship Warranty (if any), which are all incorporated herein by reference. Customer agrees that his or her signature to any one of the Contract Documents constitutes his or her receipt and acceptance of all of the Contract Documents. The parties agree that there is adequate consideration for this Proposal/Contract, the receipt and sufficiency of which is hereby acknowledged.
ACCEPTANCE OF PROPOSAL: The above prices, specifications and conditions are Satisfactory and are hereby accepted. Contractor is authorized to do the work as specified. By signing below, Customer acknowledges that Customer is the owner of the property where work is to be performed.
CUSTOMER’S RIGHT TO CANCEL: If for whatever reason you do not want the goods or services, you may cancel this agreement by providing written notice to the seller in person, by telegram, or by mail. This notice must indicate that you do not want the goods or services and must be delivered or postmarked before midnight of the third business day after you sign this agreement. If you cancel this agreement, the seller may not keep all or part of any cash down payment.
ACCORDING TO FLORIDA’S CONSTRUCTION LIEN LAW (SECTIONS 713.001 — 713.37, FLORIDA STATUTES), THOSE WHO WORK ON YOUR PROPERTY OR PROVIDE MATERIALS AND SERVICES AND ARE NOT PAID IN FULL HAVE A RIGHT TO ENFORCE THEIR CLAIM FOR PAYMENT AGAINST YOUR PROPERTY. THIS CLAIM IS KNOWN AS A CONSTRUCTION LIEN. IF YOUR CONTRACTOR OR A SUBCONTRACTOR FAILS TO PAY SUBCONTRACTORS, SUB-SUBCONTRACTORS, OR MATERIAL SUPPLIERS, THOSE PEOPLE WHO ARE OWED MONEY MAY LOOK TO YOUR PROPERTY FOR PAYMENT, EVEN IF YOU HAVE ALREADY PAID YOUR CONTRACTOR IN FULL. IF YOU FAIL TO PAY YOUR CONTRACTOR, YOUR CONTRACTOR MAY ALSO HAVE A LIEN ON YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED YOUR PROPERTY COULD BE SOLD AGAINST YOUR WILL TO PAY FOR LABOR, MATERIALS, OR OTHER SERVICES THAT YOUR CONTRACTOR OR SUBCONTRACTOR MAY HAVE FAILED TO PAY. TO PROTECT YOURSELF, YOU SHOULD STIPULATE IN THIS CONTRACT THAT BEFORE ANY PAYMENT IS MADE, YOUR CONTRACTOR IS REQUIRED TO PROVIDE YOU WITH A WRITTEN RELEASE OF LIEN FROM ANY PERSON OR COMPANY THAT HAS PROVIDED TO YOU A “NOTICE TO OWNER.” FLORIDA’S CONSTRUCTION LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED THAT YOU CONSULT AN ATTORNEY.
CHAPTER 558 NOTICE OF CLAIM
ANY CLAIMS FOR CONSTRUCTION DEFECTS ARE SUBJECT TO THE NOTICE AND CURE PROVISIONS OF CHAPTER 558, FLORIDA STATUTES.
RADON GAS WARNING
Radon gas: Radon is a naturally occurring radioactive gas that, when it has accumulated in a building in sufficient quantities, may present health risks to persons who are exposed to it over time. Levels of radon that exceed federal and state guidelines have been found in buildings in Florida. Additional information regarding radon and radon testing may be obtained from your county health department.
FLORIDA HOMEOWNERS’ CONSTRUCTION RECOVERY FUND
PAYMENT, UP TO A LIMITED AMOUNT, MAY BE AVAILABLE FROM THE FLORIDA HOMEOWNERS’ CONSTRUCTION RECOVERY FUND IF YOU LOSE MONEY ON A PROJECT PERFORMED UNDER CONTRACT, WHERE THE LOSS RESULTS FROM SPECIFIED VIOLATIONS OF FLORIDA LAW BY A LICENSED CONTRACTOR. FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A CLAIM, CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD AT THE FOLLOWING TELEPHONE NUMBER AND ADDRESS: (850) 487-1395, 2601 Blairstone road, Tallahassee, FL 32399-1039.
LIMITED WORKMANSHIP WARRANTY
Roof under workmanship warranty (if less than entire roof) ________________________
This warranty is valid only if signed by the Customer and Kelly Roofing, LLC (“Roofing Contractor” or “Contractor”). This warranty is a part of the contract between Customer and Contractor and incorporates the terms of the contract. Any warranty provided by or through Contractor is void if Customer fails to pay for any portion of the contract.
The roof applied to the building described above is warranted for workmanship for____ years from the date of completion shown above. Under this express workmanship warranty, the Roofing Contractor will at its own expense make any repairs necessary to correct roof leaks resulting from the following causes:
1) Poor workmanship of Roofing Contractor in applying roofing and flashing materials unless the failure is a result of a specified exclusion.
Contractor disclaims all liability for claims arising out of the exclusions listed below. Customer acknowledges that he/she is solely liable for all damages, whether actual or consequential, arising out of these claims. This express workmanship warranty does NOT cover the following:
1) Leaks or other damage caused by:
- a) Natural disasters including, without limitation, floods, lightning, hurricanes, tropical storms, hail, windstorms, earthquakes, and/or tornadoes, provided that the damage is not solely the result of the failure of the roof system to meet the designed wind speed.
- b) Structural failures such as cracks in decks, walls, partitions, foundations, windows, stoppage of roof drains/gutters, etc.
- c) Changes in original principal usage to which building is put unless approved in advance in writing.
- d) Erection or construction of any additional installation on or through the roofing felt after date of completion.
- e) Roof or flashing repairs by others; painting or coating without approval.
- f) Acts of God, strikes, riots, war, civil disturbances, fire, vandalism or other damage beyond Contractor’s control.
- g) Dry rot, termites, rodents, or other pests.
- h) Penetration of the roofing from beneath by rising nails.
- i) Failure of Customer to maintain the roof system and/or damage caused by foot traffic.
- j) Latent manufacturing defects of any roofing or flashing materials that materially affect their performance.
2) Damage to the building or its contents, roof insulation, roof deck or other base over which roofing felt is applied.
3) Damage to person or property caused by mold, mildew, fungi, spores, algae, microscopic organisms, hazardous chemicals, biological agents or allergens.
4) If, at any time during the term of this warranty, the subject property is exposed to windstorms or hurricanes in excess of the designed wind speed, all warranties provided by Contractor, if any, shall be deemed null and void. In addition, if Customer fails to strictly adhere to the payment terms contained in the contract, the warranty shall also be deemed null and void.
It is the Customer’s responsibility to notify Contractor in writing within three (3) days of the occurrence of any claim, defect, or deficiency arising out of work performed, services supplied, or materials provided by Contractor under the contract (“Occurrence”). Failure of the Customer to provide written notice of the Occurrence will result in the Customer waiving all claims that may be brought against Contractor because of or relating to the Occurrence, including claims arising in law, equity, contract, warranty, tort, or federal or state statutory claims. Upon receiving notice, Contractor will inspect the roof, and if the cause of the leak is within the coverage as stated above, the Contractor will arrange for repairs to be made at no cost to the Customer. If the cause of the leak is not covered by the warranty, Contractor will notify Customer that the leak is not covered and Contractor shall not be liable to Customer for the cost of repairs or damage arising from the leak. In the event leaks are not covered under the terms of this warranty, a service charge will be invoiced to the Customer. This warranty will become null and void if Customer fails to pay this service charge within 20 days of the billing date. Other than this express workmanship warranty: THERE ARE NO EXPRESS OR IMPLIED WARRANTIES WHATSOEVER INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANT-ABILITY AND FITNESS FOR A PARTICULAR PURPOSE PROVIDED BY CONTRACTOR.
Payment is past due and immediately owing for the construction services provided by Kelly Roofing, LLC (“Kelly Roofing”) at the above-referenced property. Pursuant to the express terms of your contract with Kelly Roofing, you yourself are obligated to remit payment to Kelly Roofing for any and all amounts owed under the contract. See ¶ 3 of the Terms and Conditions (“Customer acknowledges and agrees that it has an independent obligation to pay Contractor”).
This obligation is non-delegable. Under Florida law, absent an agreement to the contrary, duties assumed under a contract cannot be transferred to another party. See e.g., Pope v. Winter Park Healthcare Group, Ltd., 939 So. 2d 185, 189 (Fla. 5th DCA 2006). Therefore, in the event that all or a portion of the services provided by Kelly Roofing are covered by insurance, you ultimately are responsible for ensuring that Kelly Roofing is paid in full. The subject construction contract governing the work provided is between you and Kelly Roofing only — NOT YOUR INSURANCE PROVIDER.
If your insurance provider is for any reason withholding all or any portion of funds that you intend to use to pay Kelly Roofing for the work and/or materials provided, your obligation to pay Kelly Roofing is in no way limited, restricted, or otherwise tolled for any period of time. Please note, in accordance with Florida law and pursuant to the express terms of your contract, Kelly Roofing is entitled to not only the outstanding balance owed, but also all collection fees, including attorney’s fees, incurred by Kelly Roofing resulting from your refusal to pay, as well as 18% interest per annum accrued on all past due amounts. See ¶ 3 of the Terms and Conditions:
Customer agrees to pay interest at the rate of 1 1/2 % per month (ANNUAL PERCENTAGE RATE OF 18%), unless otherwise required by law, on the balance of any and all unpaid amounts. Payments received shall be applied first to interest on all outstanding invoices and then to the principal amount of the oldest outstanding invoices…
Customer acknowledges and agrees that it has an independent obligation to pay Contractor. If Customer does not make payment, Contractor shall be entitled to recover from Customer all costs of collection incurred by Contractor, including attorney’s fees, costs, and expenses incurred whether or not litigation is initiated…
If payment is not immediately made in accordance with the terms of your contract, Kelly Roofing will be forced to proceed with all available legal means in pursuit of same. Kelly Roofing reserves all rights and remedies.